• Skip to primary navigation
  • Skip to main content
  • Skip to primary sidebar
  • Skip to footer

MDC Systems

Providing Expert Solutions
for Projects Worldwide


PH: (610) 640.9600 | FX: (484) 301.0969

MENUMENU
  • About
  • Services
    • Construction Claims
    • Construction Management
    • CPM Scheduling/TIA®
    • Construction Dispute Resolution
    • Forensic Services
    • Expert Witness
    • Project Management
    • Risk Assessment
    • Modeling, BIM, Schedule, WUFI®
    • Energy/Sustainability Consulting
    • Government Services
    • Benchmarking
  • Professionals
  • Projects
    • Projects By Category
      • Building Diagnostics
      • Construction Claims
      • CPM Scheduling
      • Owner Issues
      • Project Management
      • Time Impact Analysis®
    • Projects by Industry
      • Commercial
      • Educational
      • Government
      • Industrial
      • Institutional
      • Pharmaceutical
  • Articles & Seminars
    • Seminars
    • Articles
  • Brochures
    • General Overview (PDF)
    • Forensic Engineering (PDF)
    • Schedule Analysis TIA (PDF)
    • Building Diagnostics (PDF)
    • Green Building & Sustainability (PDF)
  • MDCAdvisor®
  • Contact

Scheduling Project

Client Name: Black & Veatch

MDC Systems® was retained by our client to determine if the utility had contributed in any material way to the problems associated with either the removal or installation of the new generators. MDC Systems® developed a detailed analysis of the problems encountered during the execution of the removal and installation work. MDC Systems® determined that much of the delay in the installation of the generators was due to delay by a subcontractor responsible to Raytheon. MDC Systems® also determined that additional delays were the result of inadequate verification by the contractor. Thus, the majority of the underlying conditions that caused the excess costs were not due to problems created by our client.

Our client contracted with a nuclear service company to remove the existing steam generators and transport and install the new units. During the course of installation, a number of conditions arose that the contractor believed were outside the scope of its responsibility and formed the basis for additional compensation. Upon close-out of the project, the contractor sent our client a request for additional compensation totaling $6 million. The contractor identified “unforeseeable” field conditions, lost productivity and inefficiency by the field forces as the cause of its excess costs.

MDC Systems® also developed a damage analysis that quantified the utility’s recoverable costs and assisted in presenting our client’s position to the contractor. This resulted in a favorable settlement for our client.

Post Views: 174

You may like:

  • Parking Garage Assessment
  • U.S. Federal Office Building and Courthouse
  • Indiana Manufacturing Plant Project
  • Nassau County Community College

Primary Sidebar

Latest News

  • MDCSystems® Taking Off with Commercial Drones
  • MDC Advisor® Expert Newsletter
  • Change Orders: Maximizing Benefits for Owners
  • Privatization of American Water Utilities
  • Building Information Modeling – Boon or Bane?
  • Shipyard Contracts: New Construction vs. Ship Repair
  • MDC Advisor® Expert Newsletter
  • Why is there a Labor Overrun?
  • Avoiding Death by a Thousand Cuts
  • Sustainability – Un-Definable Success in a Defined World
  • Modeling of a Residential Photovoltaic System and Model Validation Using Measured Data
  • Time Impact Analysis (TIA®)
  • Risk Management: Insuring Continuity of Supply
  • More Than Just Counting Rainy Days: Documenting Weather Delays

Footer

Headquarters United States

MDC Systems®

1800 E. Lancaster Ave.
Suite -P Paoli, PA 19301
Map/Directions

Phone and Fax

Phone: 610.640.9600
Fax: 484.301.0969

Email

Robert C. McCue, PE
mccue@mdcsystems.com

Popular News

  • MDC Advisor® Expert Newsletter
  • Overcoming Complexity-Intellectual Foundation of the Concepts
  • CAD and Models – If 4-D is good, then 5-D must be better
  • Forensic Project Management
  • Design-Build – What Every Underwriter Should Know

Associations

Chartered Institute of Arbitrators
American Bar Association
American Society of Heating, Refrigerating and Air-Conditioning
International Code Council
Forum on Construction Law
Building Construction Association
National Society of Professional Engineers

©1998 by MDCSystems, Inc. MDCSystemsSM, Time Impact AnalysisSM, TIASM, Capital Project Management SystemTM, CPMSTM, Forensic Project ManagementSM, FPMSM, are services marks and/or trademarks of MDCSystems, Inc.

Copyright © 2023 · Slipstream on Genesis Framework · WordPress · Log in